United States: Contractor Authority Over Means And Methods

Last Updated: July 21 2015
Article by Luke D. Martin

A central principle of construction contracts is that, where a contractor (a) commits to construct in accordance with plans and specifications (b) provided by the owner (c) in exchange for payment of a firm, fixed price, the contractor controls its means and methods, unless the plans and specifications clearly dictate a particular means or method. (For example, the structural engineer may specify a particular jacking procedure for raising a space frame.) When the owner, after contract execution, requires the contractor to perform in a different manner than the contractor planned, even though the contractor's original plan also meets the contract requirements, the contractor is due compensation for the increased costs it suffers as a result of this direction. This principle was again at play in Columbia Construction Co. v. General Services Administration.

In 2009, Columbia Construction Co. ("Columbia") contracted with the General Services Administration ("GSA") to upgrade an existing IRS service center in Andover, Massachusetts. The upgrade included a whole building renovation and, pertinent to this case, included an upgrade of the building's security system. Columbia subcontracted with Wayne J. Griffin Electric, Inc. ("Griffin") for Griffin to provide the electrical, communications, and security contract work.

The security system work was detailed in multiple specifications and drawings in the contract documents. The pre-existing building security system was an "open" system, with security cabling not run in conduit or raceways. According to the plans and specifications, in the renovated building this security wiring was required to be "concealed or in conduit (EMT) unless specifically approved in writing by the contracting officer."

The specifications defined "concealed" as follows: "covered completely by building materials, except for penetrations (by boxes and fittings) to a level flush with the surface as necessitated by functional or specified accessibility requirements." Griffin interpreted these specifications to mean that it would be permitted to install security cabling in cable trays either above the ceiling or underneath the raised access floor, because this would "cover" the security cabling "with building materials." When GSA observed Griffin installing security cable on cable trays in the raised access floor system, the GSA Contracting Officer ("CO") immediately directed Griffin to stop this work. GSA then instructed Columbia in writing to install cabling in conduit "per the contract."

Griffin noted its disagreement with this interpretation, but began installing security wiring in cable tray per the GSA direction. Griffin then submitted a request for equitable adjustment ("REA") to Columbia for the costs it claimed it would incur as a result of being forced to install security cable in conduit. Columbia passed this REA through to the GSA. After a series of meetings to discuss security cabling, GSA rejected this REA and required Griffin to continue installing security wiring in conduit.

Columbia submitted a certified claim to GSA on behalf of Griffin, which the CO denied. Columbia then appealed this decision to the Civilian Board of Contract Appeals (the "Board"), the judicial body which governs appeals from CO decisions of the GSA, Department of Veterans Affairs, and other civilian governmental bodies.

The Board ruled in favor of Columbia and Griffin. The Board noted that the contract gave the contractor the option of using conduit or another installation method that concealed the security cabling by covering it completely in building materials. The Board rejected the GSA's argument that the drop ceiling and the raised access flooring did not meet the definition of "building materials" under a plain interpretation of the contract. Considering the contract as a whole, and the various other specifications that clearly showed that "concealed" could include installation below the raised access flooring or above the drop ceiling, the Board held that it would be unreasonable to interpret the contract to exclude security cabling from this permitted installation method. Because "GSA unreasonably stopped [Griffin's] planned installation" it was required to "pay the increased price for demanding that the security cabling be installed in conduit."

This case demonstrates once again that the Government cannot require more than its plans and specifications require without paying its contractor additional compensation. It is also of interest because of what was revealed in discovery. The Government produced a document from a GSA electrical engineer that essentially admitted that the GSA requirement to use conduit exceeded the security system specifications, and noted that "if this case were to proceed forward, the government would likely be found responsible for a large portion of the stated costs..." The document also detailed a lack of consensus among GSA personnel as to whether conduit was required for this installation. The Board cited this document in its decision, although it did not state that it based its decision on it. The document was certainly harmful to the Government's position, and it brings to mind another practice point: be aware that non-privileged project documentation and correspondence is likely discoverable and could one day wind up in the hands of potential adversaries. As such, make sure that such documentation is accurate and factual, but be wary of including negative discussions of issues or "lessons learned" in such written documentation. In addition, be sure your counsel is aware of any such documentation when you seek guidance about the merits of your case.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions