UK: Adjudication Watch - November 2016

In this latest 'Adjudication Watch' our construction team reviews key cases relating to adjudication from the last few months.

Key point: Can an adjudicator decide an issue that neither party has raised?

Stellite Construction Ltd v Vascroft Contractors Ltd [2016]

The background to this Technology and Construction Court (TCC) decision is that Stellite engaged Vascroft to construct the shell and core of a house in Hampstead, London under a contract which incorporated the terms of the JCT Standard Building Contract Without Quantities 2011 (the Contract).

The Contract provided that Vascroft was entitled to extensions of time for "Relevant Events" and Stellite was entitled to liquidated damages in the event that the Works were delayed. The completion of the Works was delayed and Stellite claimed liquidated damages. When Vascroft refused to pay, the dispute was referred to adjudication. The adjudicator made the following findings:

  1. time for completion had been set at large;
  2. no liquidated damages were therefore due to Stellite; and
  3. having decided that time was at large, a reasonable time for completion was by no later than 5 March 2016

In Part 8 proceedings, Stellite sought declarations that the adjudicator's decision was unenforceable on the basis that the adjudicator had breached the rules of natural justice and acted outside of his jurisdiction.

Ground 1: Natural justice

On the first ground of challenge, Stellite contended that the adjudicator was in breach of the rules of natural justice for having decided that time was at large without allowing either party to comment on the issue. The question of whether parties have been given a fair opportunity to set out their respective positions will depend on the facts - if the adjudicator acts in breach of the rules of natural justice, the courts will not enforce the decision.

Mrs Justice Carr held that both parties had been given sufficient opportunity to comment on the issue of whether time was at large, so there was no breach of the rules of natural justice.

Ground 2: Jurisdiction

Stellite further contended that the adjudicator had acted outside of his jurisdiction by determining a reasonable time for completion, arguing that this was not an issue that the parties had asked to be decided and was outside the scope of a claim for liquidated damages.

The principle of what falls within the scope of an adjudicator's jurisdiction is determined by the nature, scope and extent of the dispute identified in the Notice of Adjudication.

The Judge found that the adjudicator had exceeded jurisdiction in this case by holding that a reasonable time for completion was 5 March 2016. Whilst the Court considered that it was a "logical next step" to determine a reasonable completion date, the adjudicator did not have the requisite jurisdiction as it would only be relevant to a claim for unliquidated damages. This part of the adjudication decision was therefore severed from the rest of the decision, which would survive.

The decision highlights:

  1. the difficulty that a party faces when it seeks to argue that there has been a material breach of the rules of natural justice. The Judge highlighted that it would be a rare case where there has been a breach of the rules of natural justice. To be able to succeed with this type of challenge, a party will need to show that the adjudicator has strayed significantly outside the ambit of the matters referred to adjudication and without giving the parties an opportunity to comment on the information intended to be relied upon in coming to any decision; and
  2. that, where practical and possible, a party may be able to sever an adjudicator's decision, allowing the uncontroversial parts to stand. 

Key point: the enforcement of adjudication decisions remains hard to challenge successfully

Ground Developments Ltd v FCC Construccion SA [2016]

This long and detailed judgment provides a helpful summary of previous authorities on the enforcement of adjudicators' decisions and reaffirms the approach of the TCC to enforcement.

Ground Developments Ltd (GDL) was engaged by Merseylink Civil Contractors Joint Venture (JV) to carry out ground engineering works on the Mersey Gateway project, a new six-lane toll bridge to be constructed over the Mersey. GDL started work without a formal contract in place but did write, setting out the terms under which it was carrying out those works. The JV failed to respond to this letter or to challenge the terms which GDL had cited.

GDL subsequently commenced an adjudication for payment of sums applied for, but acknowledged the position regarding the nature of the contract between the parties. The JV challenged the appointment of the adjudicator on a number of jurisdictional grounds and reserved its position regarding enforcement proceedings. The adjudication continued, however, and the adjudicator awarded GDL the sums applied for. It was also decided that the parties' contract was based on the letter sent by GDL to the JV which they had failed to acknowledge.

The JV sought to challenge the adjudicator's decision on the basis of seven defences. Mr Justice Fraser rejected each of these defences in turn deciding that the adjudicator had not breached the rules of natural justice and had not exceeded his jurisdiction.

The decision highlights:

  1. the difficulties an unsuccessful party faces when challenging an adjudicator's decision; and
  2. the familiar scenario where parties are in dispute as to the existence and form of a contract and the impact this has on the adjudicator's decision.

Key point:  the test for "apparent bias" is objective and demanding

Paice & Anor v Harding (t/a MJ Harding Contractors) [2016]

This is the latest (and hopefully the last) chapter in a long-running dispute. This time it was the attempt by the employers (Mr Paice and Ms Springall - PS) to enforce the adjudicator's decision in what was the fifth adjudication between the parties.

The contractor, Harding, challenged the adjudicator's decision, with the substantive challenges being that:

  1.  the adjudicator's decision was late; and
  2. the adjudicator showed apparent bias.

Ground 1:  Late decision

Harding argued that it had not agreed to extend the time for the adjudicator (Mr L), to make his decision, and therefore the decision was given out of time.

Harding did not accept Mr L's jurisdiction, having challenged his appointment on the basis that the employers had referred the dispute under the wrong procedural rules. In terms of the extension of time for provision of Mr L's decision, Harding sought to argue that although it had confirmed that it would agree to an extension for a non-binding determination, it had otherwise reserved its position.

The TCC dismissed this argument. An agreement to extend time for an adjudicator's decision is likely to be taken at face value, whatever reservations continue to be expressed by a party in relation to the adjudicator's jurisdiction. 

Ground 2: Apparent bias

This contention arose from the complex history of the dispute.

The adjudicator in the fourth adjudication (Mr S) had decided that the value of the final account had been overstated in the third adjudication and ordered Harding to repay £325,484 to PS (out of the £397,012 awarded).  However, Harding had successfully resisted enforcement of Mr S' decision on the grounds of apparent bias and subsequently made a formal complaint to the nominating body, the RICS, in respect of Mr S' conduct of the adjudication. 

In the RICS disciplinary proceedings that arose from Harding's complaint, Mr L gave a character reference for Mr S and Harding argued that Mr L was therefore guilty of apparent bias.

The TCC held that Mr L did not have an obligation to disclose the fact he had provided a character reference for Mr S and his view of Mr S could not reasonably be considered to impact upon his position as adjudicator in the fifth adjudication.

The test for apparent bias is objective and is whether an informed and fair minded observer, with knowledge of all the relevant circumstances, would conclude that there was a real possibility of bias. The TCC found this not to be the case here and rejected Harding's challenge on this basis.

Key point: the adjudication process has a basic requirement of fairness 

Beumer Group UK Ltd v Vinci Construction UK Ltd [2016]

Beumer (the sub-contractor) sought to enforce an adjudicator's decision against Vinci (the main contractor) in relation to works Vinci had engaged Beumer to undertake on the South Terminal baggage handling system at Gatwick Airport under an NEC3 subcontract. Vinci challenged the adjudicator's decision on the grounds that there had been a breach of the rules of natural justice and the adjudicator showed apparent bias.

Beumer had engaged the services of Daifuku Logan (sub-sub-contractor). A dispute arose between Beumer and Vinci at the same time as a disagreement between Beumer and Logan. Beumer referred both disputes to adjudication on the same day. The same adjudicator was appointed to act in both adjudications. Vinci was not told about the adjudication between Beumer and Logan, nor was Vinci informed that the same adjudicator was appointed in both adjudications.

The TCC held that the adjudicator was in breach of the rules of natural justice. The adjudicator should have told Vinci that he was acting as adjudicator in another dispute involving Beumer, regardless of the fact that it related to the same project. Beumer had put forward inconsistent cases on the completion date (the "Airport Operational Date" under the contract) in the two concurrent adjudications; this factual inconsistency could have been relied on by Vinci, who were denied the opportunity of making this submission.

Mr Justice Fraser was critical of Beumer's actions in the two adjudications:

"I take a very dim view of the propriety of behaviour where Party A says in one set of adjudication proceedings with Party B "the works were complete on 16 December 2015" and, in relation to the very same works (or at least a sub-set of the works) on the same project states in another set of adjudication proceedings with Party C "the works are not yet complete, you are liable to pay liquidated damages" "(Paragraph 25).

The decision highlights:

  1. the court's view that it is difficult, if not impossible, for an adjudicator to be permitted to conduct another adjudication involving one of the same parties without disclosing the existence of that appointment from the outset. There is an obvious risk that a failure to do so will result in a finding of apparent bias; and
  2. the extent of the requirement of disclosure by parties in adjudication. Mr Justice Fraser stated that it was appropriate for there to be disclosure of the relevant materials pertaining to Beumer's inconsistent case. Whether this applies in other cases will be a matter of fact and degree.

If you have any queries on these cases, or adjudication generally, please call Ashley Pigott or Lindsay Hammond.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Events from this Firm
19 Sep 2019, Seminar, Birmingham, UK

Providing GCs, Heads of Legal and senior in-house lawyers with timely, topical and practical legal advice on a variety of topics.

26 Sep 2019, Seminar, London, UK

Providing GCs, Heads of Legal and senior in-house lawyers with timely, topical and practical legal advice on a variety of topics.

8 Oct 2019, Seminar, Birmingham, UK

Supporting the development of paralegals, trainees and lawyers of up to five years' PQE by providing valuable knowledge and guidance together with practical tips.

Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions