United States: The Court Of Appeal In England & Wales Curtails Use Of Liquidated Damages For Delay

In international construction arbitration, the use of liquidated damages to address the consequences of failure by a contractor to finish the works by the date set for completion is widespread. Typically, the contractor completes the works late and absent any compelling arguments that the liquidated damages regime is an unenforceable penalty, liquidated damages for the delay are readily calculated and deducted. However, the Court of Appeal in England & Wales in Triple Point Technology, Inc. v PTT Public Company Ltd [2019] EWCA Civ 230 has shattered orthodox thinking on how to apply a clause imposing liquidated damages for delay to completion in circumstances where the contractor never actually achieves completion because his employment is terminated. In such scenarios, it was common for arbitral tribunals to award liquidated damages between the original date for completion and either the later date of termination or the date at which completion was ultimately reached post termination using another contractor. Triple Point Technology, Inc. v PTT Public Company Ltd has ruled that such approaches are incorrect in such a scenario and unless express words in the clause imposing liquidated damages state otherwise, the liquidated damages regime has no application in such a scenario because the contractor has not actually completed the works or handed over the works to the employer.

This is a very important ruling from the Court of Appeal and one with fundamental consequences for those employers and contractors currently involved in relying on a liquidated damages regime where there has been a termination after the original date for completion. In this Alert we consider the Court of Appeal's analysis and how the various and commonly used liquidated damages regimes maybe adjusted to take account of Triple Point Technology, Inc. v PTT Public Company Ltd.

The Approach of the Court of Appeal

In Triple Point Technology, Inc. v PTT Public Company Ltd the express liquidated damages clause stated:

If CONTRACTOR fails to deliver work within the time specified and the delay has not been introduced by PTT, CONTRACTOR shall be liable to pay the penalty at the rate of 0.1% (zero point one percent) of undelivered work per day of delay from the due date for delivery up to the date PTT accepts such work, provided, however, that if undelivered work has to be used in combination with or as an essential component for the work already accepted by PTT, the penalty shall be calculated in full on the cost of the combination.

It was not in dispute that the contract had been terminated before the contractor, Triple Point Technology Inc., had completed the work and so PPT had not accepted such work. The Court of Appeal explained that the authorities in cases where a contractor fails to complete the works and a second contractor steps in showed three different approaches to clauses providing liquidated damages for delay:

  • The clause does not apply at all.
  • The clause only applies up to termination of the first contract.
  • The clause continues to apply until the second contractor achieves completion.

The Court of Appeal considered that a House of Lords decision from 1912 was the most compelling and in any event had to be followed by the Court of Appeal since it "was a decision of our highest court." In British Glanzstoff Manufacturing Co. Ltd v General Accident, Fire and Life Assurance Co. Ltd 1913 SC (HL) Clause 24 of the contract provided:

24. If the contractor fail to complete the works by the date named in clause 23, or within any extended time allowed by the architect under these presents, and the architect shall certify in writing that the works could reasonably have been completed by the said date, or within the said extended time, the contractor shall pay or allow to the employer the sum of £250 sterling per week for the first four weeks, and £500 per week for all subsequent weeks as liquidated and ascertained damages for every week beyond the said date or extended time, as the case may be, during which the works shall remain unfinished, except as provided by clause 23, and such damages may be deducted by the employer from any moneys due to the contractor.

The House of Lords decided that the liquidated damages regime only applied if the contractor actually completed the works – if he is "ousted from the works by the employers under their powers" then the contractor has not completed the works. Lord Justice Jackson gave the leading judgement and could "see much force in the House of Lords' reasoning in Glanzstoff. In some cases, the wording of the liquidated damages clause may be so close to the wording in Glanzstoff that the House of Lords' decision is binding. That is a decision of our highest court, which has never been disapproved." Jackson LJ concluded:

"Let me now turn to Article 5.3 in the present case. This clause, like clause 24 in Glanzstoff, seems to be focused specifically on delay between the contractual completion date and the date when Triple Point actually achieves completion. The phrase in article 5.3 "up to the date PTT accepts such work" means 'up to the date when PTT accepts completed work from Triple Point'. In my view Article 5.3 in this case, like clause 24 in Glanzstoff, has no application in a situation where the contractor never hands over completed work to the employer."

The Court of Appeal also looked at several U.S. authorities and articles including an article in the Montana Law Review for 1942 by B. Johnson, Damages: liquidated damages for delay in an abandoned construction contract. However, as in England, the American cases went in both directions and thus did not determine the issue for the Court of Appeal. However, as shown in the sample clause, the U.S. government expressly addresses in its standard construction contract the application of liquidated damages post termination:

Liquidated Damages-Construction (Sept 2000)

I. (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of ____________ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.
II. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Amending the Standard Form Clauses

As discussed above in the opening, one commonly held or orthodox view has been that a liquidated damages regime applies up to date of termination and general damages may be applicable post termination. Jackson LJ said that "In my view, the question whether the liquidated damages clause (a) ceases to apply or (b) continues to apply up to termination/abandonment, or even conceivably beyond that date, must depend upon the wording of the clause itself. There is no invariable rule that liquidated damages must be used as a formula for compensating the employer for part of its loss." The wording of the clause is of fundamental importance and so we set out below suggestions for how certain standard form clauses may be amended to allow the orthodox view. One also needs to be mindful that contractors may, in turn, now be more keen to assert that liquidated damages cannot be levied in the event of termination of the contractor's employment.

JCT Contracts1

To accommodate the orthodox position, the Schedules of Amendments would need to amend the liquidated damages clause and the provision dealing with payments on termination. Using the Design & Build form as an example, possible amendments (in bold) would be:

2. 29.2 - Delete lines 1 and 2 and substitute:

"A notice from the Employer under this clause 2.29.2 shall state that for the period between the Completion Date and the date of practical completion of the Works or that Section or, if earlier, the date on which the Contractor's employment under this Contract is terminated or this Contract is otherwise terminated for any reason:"

8.7.4 - Delete and substitute:

Not later than 5 days after the due date for payment in clause 8.7.3A the Employer shall provide the Contractor with an account of the following (Termination Account):

I. the total value of the Works executed and Site Materials as at the date of termination (Termination Value);
II. the total of the amounts previously paid to the Contractor under this Contract (plus any amounts to be credited to the Employer in respect of the period to the date of termination, e.g. liquidated damages accrued due under clause 2.29) (Payments and Credits);
III. (if relevant) the total further amount (additional to the Termination Value) which would have become payable to the Contractor for the fulfilment of all his outstanding obligations under this Contract, had it not been terminated (Prospective Works Value); and
IV. (if relevant) the total amount of the costs and expenses reasonably and/or necessarily incurred by the Employer, including any under clause or 8.7.1, and/or any other loss or damage for which the Contractor is liable, whether resulting from the termination or otherwise, including any loss or damage arising as a result of any delay in the completion of the Works beyond the later of the Completion Date under this Contract and the date on which the Contractor's employment under this Contract is terminated or this Contract is otherwise terminated for any reason (Employer's Costs and Losses).
(Employer's Costs and Losses).


Clause 8.8, amongst others, dealing with delay damages in the conditions of contract for engineering, procurement and construction (EPC)/turnkey projects, also needs to be amended to accommodate the orthodox position of allowing liquidated damages for delay up to the date of termination (as shown in bold below):

"If the Contractor fails to comply with Sub-Clause 8.2 [Time for Completion] the Employer shall be entitled subject to Sub-Clause 20.2 [Claims for Payment and/or EOT] to payment of Delay Damages by the Contractor for this default...such payment of Delay Damages shall be payable even if the Contractor's employment under this Contract is terminated or this Contract is terminated for any reason whatsoever."

LOGIC3 Edition 2

Article 35 dealing with liquidated damages may, amongst other Articles, need to be amended to make it clear that liquidated damages can be levied if there is a failure to complete the works in circumstances where the contractor is "ousted from the works." For example, Article 35.1 may be amended with the words in bold text as follows:

"If the CONTRACTOR fails to complete any of the items listed in Appendix 1 to Section 1 – Form of Agreement in accordance with the relevant date included in the SCHEDULE OF KEY DATES and/or fails to achieve the requirements of the CONTRACT in respect to any other items listed under the heading clause 35.1 – Liquidated Damages in said Appendix 1 the CONTRACTOR shall be liable to COMPANY for Liquidated Damages such payment of Liquidated Damages shall be payable even if the CONTRACTOR'S employment under this Contract is terminated or this CONTRACT is terminated for any reason whatsoever.


1 The Joint Contracts Tribunal (JCT) produces standard forms of contract for construction, guidance notes and other standard documentation for use in the construction industry.

2 The International Federation of Consulting Engineers (commonly known as FIDIC, an acronym for its French name: Fédération Internationale Des Ingénieurs-Conseils) is an international standards organization for the consulting engineering & construction best known for the FIDIC family of contract templates

3 These standard contracts for the U.K. offshore oil and gas industry have been developed by the Standard Contracts Committee (formerly CRINE Standard Contracts Committee) and issued by LOGIC for use in the U.K. offshore oil and gas industry.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions