Worldwide: The Emerald Book: The New FIDIC Tunnelling Contract

Last Updated: 9 September 2019
Article by Jeremy Glover

On 7 May 2019 at the World Tunnelling Congress 2019, in Naples, FIDIC launched a new contract, the Conditions of Contract for Underground Works ("the Emerald Book"). Taking the 2017 Yellow Book as its starting point, the new Emerald Book is a joint initiative between FIDIC and the International Tunnelling and Underground Space Association ("ITA") which had set up a joint task group back in 2014.

The Introduction to the new Contract identifies three "unique features" of underground work:

"– the method of excavation and ground support are major factors for the successful realization of the project, and therefore part of the Works;

– physical access to the Works is often limited to just a few locations or even a single location, which places serious constraints on construction logistics and the environment;

– the land, beneath which the Works are to be constructed, typically belongs to a number of third parties."

Laying on top of these three features is the difficulty in predicting, with any certainty, the ground conditions for the entirety of the underground works, meaning that considerable thought had to be given as to how to maintain FIDIC's fundamental principle of balanced risk sharing and/or allocation.

The Geotechnical Baseline Report and unforeseeable ground conditions

The Emerald Book seeks to deal with the difficulties created by unforeseeable ground conditions primarily through the use of the Geotechnical Baseline Report ("GBR"). This is intended to be the sole source or contractual document that describes the anticipated subsurface conditions that are likely to be encountered during the execution of the Works. The GBR should also define the subsurface condition or ground-related risks between the Employer and the Contractor. Such is the importance of the GBR that Appendix A to the Emerald Book provides guidance as to what the GBR should contain. Further, the Emerald Contract provisions are based on the Employer including a GBR and are not intended for use where the Contractor is to construct the Works in accordance with a detailed design provided by the Employer.

Two of the other key documents are the Completion Schedule and the Schedules of Baselines. This is a reflection of the fact that the Time for Completion is largely influenced by ground conditions. The Completion Schedule sets out the Time for Completion of the Milestones, which are "based on and consistent with the production rates provided by the Contractor in the Baseline Schedule". The Schedule of Baselines sets out details of the anticipated activities or items of work which are "consistent with the conditions described in the GBR".

The idea is that the Contractor enters production rates and durations for the excavation and lining works corresponding to each drive and/or other area of work, which are deemed to allow for the time the Contractor needs to complete that activity. In defining the duration, the Contractor is expected to take into account: economies of scale, learning curve, availability and deployment of resources, safety requirements, working space, accessibility, and working time.

The definition of "physical conditions" not only includes natural physical conditions, physical obstructions (natural or man-made) and pollutants but also "reactions of the ground to Excavation", a good example of the contract being tailored to tunnelling works. The excavation works need to be constantly monitored and there is also a requirement that the Contractor submits to the Engineer on a daily basis its interpretations of the subsurface and surface monitoring results.

By new sub-clause 13.8.3, the time allowed for the excavation and lining works in the Completion Schedule and/or the Programme, may be reassessed (and this means reduced or extended) by the Engineer who, when making the reassessment, applies the production rates provided by the Contractor in the Schedule of Baselines. There is a similar approach to cost, with the Emerald Contract providing a flexible mechanism for remuneration according to ground conditions, foreseen and unforeseen.

The idea is that the Employer, who prepares the GBR, takes the risk for unexpected or unforeseeable underground conditions, which is the standard FIDIC Yellow Book approach. However, the Employer, whilst taking the burden of conditions that are worse than predicted, will get to enjoy the benefit if the conditions for the excavation and lining works turn out to be better than anticipated. In other words, if ground conditions actually encountered differ from those set out in the GBR, and the critical path is affected, the Time for Completion will be adjusted: increased if the conditions are worse but shortened if more favourable conditions are encountered.

Dispute avoidance and advance warning

The Emerald Contract comes some 17 months after the release of the 2017 Second Edition of the Rainbow Suite. Unsurprisingly, it follows the dispute resolution mechanisms found in Clauses 20 and 21. Further, the use of the GBR, and the efforts taken to provide guidance on how to draft the GBR, should help ensure that the allocation of the risks of underground conditions are as clear as possible, something which should also help avoid and reduce the scope for disputes.

Upon the release of the 2017 Suite, everyone remarked on its size. The contracts almost doubled in length. The Yellow Book General Conditions increased from 63 pages to 119 (or 69 pages to 132 including the DAAB Agreement and Index of Sub-clauses). The Guidance and Annexes increased from 30 pages to 68. The Emerald Book is even longer. For example, there are now 104 Definitions, an increase of 14. However, that is not so surprising, given the need to make the contract specific to tunnelling and the importance of the GBR to the contractual scheme.

One of the new definitions comes at sub-clause 1.1.116. However, the introduction of the Contract Risk Register is not something that needs to be unique to tunnelling. Indeed, it could be seen as part of FIDIC's continued attempts to promote real-time dispute avoidance.

Whilst the idea of the Contract Risk Register is nothing new in itself, it is new to the FIDIC Form. Here, the need for one suits the demands of the tunnelling contract, including the need to ensure that a close eye is kept on the changing ground conditions and progress. The Contract Risk Register is required to identify both relevant risks, and the actions which are to be taken to avoid or reduce those risks.

Under the Emerald Book scheme, the Contractor must complete and maintain the Contract Risk Register and prepare and maintain the Contract Risk Management Plan to manage and control any risks identified. Both must be regularly updated. Further, regular Contract Risk Management meetings are to be held. Sub-clause 1.16 (b) also requires that the Contractor has procedures in place to ensure that certain actions can be taken. These include issuing advance warning notices under sub-clause 8.4 (which deals with Advance Warning) and/or that meetings are called whenever a "known, probable or uncertain future event" is likely to:

"(a) adversely affect the work of the Contractor's Personnel;

(b) adversely affect the performance of the Works when completed;

(c) increase the Contract Price; and/or

(d) delay the execution of the Works or a Section or any Milestone."

Whilst the idea of early warning could be found in the 1999 Form, with sub-clause 8.3 including a requirement for the Contractor to give notice of "specific, probable future events or circumstances which may adversely affect the work", it was the 2017 Edition that drew firm attention to the importance and potential value to the project of giving early or advance warning. Sub-clause 8.4 imposed a requirement on the Contractor, Employer and Engineer to give early warning of potential problems. The introduction here of the Contract Risk Register reinforces this further.

FIDIC: the future

There is no change in the Emerald Book in respect of the references to the FIDIC Golden Principles, which remain part of the guidance listed in the Special Provisions. And whilst the Advisory Notes where the project uses BIM have been modified slightly, in that there are changes to the list of sub-clauses that may be affected by BIM, for subsurface projects there is no real change. The "Technology Guideline" and "Definition of Scope Guideline Specific to BIM" documents are still awaited.

However, the introduction of the Emerald Book may be seen as timely given the increasing number of infrastructure and energy projects with underground elements. It also fits in with the gradual expansion of the use of the FIDIC Form globally. FIDIC has recently confirmed that it has agreed a five-year non-exclusive licence for the use of the 2017 Suite of Contracts with the World Bank. The Contracts are also going to be translated into Arabic, Chinese, French, Portuguese and Spanish, a move which will encourage their use. No doubt there will be further new developments soon.

International Quarterly is produced quartely by Fenwick Elliott LLP, the leading specialist construction law firm in the UK, working with clients in the building, engineering and energy sectors throughout the world.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions