UK: Payment Provisions In Construction Contracts

Last Updated: 9 November 2015
Article by Jonathan More

When the amendments to the Housing Grants (Construction and Regeneration) Act 1996 ("the Construction Act") were introduced by Part 8 of the Local Democracy, Economic Development and Construction Act 2009 ("the New Act") it was not entirely clear how the changes in the payment provisions section would impact on the behaviour of parties to construction contracts. In the year since our last Annual Review the first wave of case law relating to these amended provisions has been reported. The message appears relatively clear; employers, get the payless notice process wrong at your peril. However, as is so often the case when new law develops, even relatively clear legal principles often give rise to spin off issues, and questions.

Jonathan More provides a practical guide through the relevant cases.

The statutory requirements

First, a brief reminder of the relevant statutory provisions.

Payment notices

In its original form the Construction Act set out that the payer had to give notice specifying the amount of the payment made or proposed to be made, and the basis upon which the amount is calculated. There was no obvious consequence for failing to comply with this requirement, indeed, as it was only the employer who could issue such notices it seemed to duplicate the certification process common in most construction contracts, and was often simply ignored.

The New Act amendments require construction contracts to provide that a payment notice is issued for every payment provided for by the contract. The sum contained in a payment notice is "the notified sum". The person whom issues the notice is dictated by the contract, and can be either the payer, a "specified person" as dictated by the contract (i.e. the Architect or Contract Administrator) or by the payee itself. The notice must specify:

(i)   the sum that the person giving the notice considers to be due or to have been due at the payment due date in respect of the payment; and

(ii)  the basis on which that sum is calculated.

Note the basis of the figure in the notice is what is considered to be due.

There is now a consequence for failure to issue a payment notice as required; the payee may issue a "default" payment notice stating the amount considered to be due and the basis for calculation. This amount is contained in the payment notice, or the "default" payment notice, is the notified sum.

These changes are important because the New Act requires that the payer is under an absolute obligation to pay the notified sum subject to whether or not a payless notice is issued. There is no language requiring this sum to be "proper value", the sum simply has to be "notified".

Payless notices

Previously there was a mechanism for a payer to avoid paying a sum due if there were grounds to do so by issuing a notice of intention to withhold payment.

The New Act amendments mirror this very closely, the key change being the obligation on the payer to pay the "notified sum" if no payless notice is issued.

A payless notice must state the sum considered to be due on the date the notice is served and the basis on which that sum is calculated, and must be issued within the requisite time requirements in the contract.

The key legal principles from case law

As a result of the recent case law, reviewed in more detail below, the following principles will be applied to payment provisions in construction contracts:

(i)   In respect of interim payment applications, and absent fraud, where no valid payless notice has been issued, the contractor will be entitled to the amount applied for irrespective of the true value
of the work carried out.

(ii)  An application for payment following termination of a contract, is distinguished from the above principle either:

  • on the basis that the contract provides for a proper valuation of work post-termination and not simply a notified sum, or
  • that, as a consequence of the contract termination, the next application for payment will be the final one, with no further interim applications or payments due.

(iii) To qualify as a valid payment notice, an application for payment should:

  • be clearly stated as being a formal application for payment and put the payer on proper notice, and
  • comply with the contractual requirements and timetable for making an application for payment.

(iv)  Even in cases where a valid payless notice has not been issued there may be sufficient unusual circumstances which may restrict enforcement of an adjudication decision.

ISG Construction Ltd v Seevic College1

The case which provides us with the first key principle is ISG v Seevic.

The facts

This application for summary judgement by ISG revolved around two adjudications. The first ("Adjudication 1") decided that Seevic required to pay the full amount of ISG's Application No. 13 for an interim certificate. Seevic had served neither a payment notice nor a payless notice. This sum in question was circa £1m. The second ("Adjudication 2"), before the same adjudicator, decided that the proper value of ISG's works as at the date of Application No. 13 was significantly lower, at £300,000.

Seevic did not comply with the decision in Adjudication 1, and simply paid the balance deemed due as the value of the works i.e. £300,000.

The application made by ISG was for (i) enforcement of the decision in Adjudication 1, and (ii) a declaration that the decision in Adjudication 2 was invalid for want of jurisdiction, as this dispute was the same or substantially the same as that decided upon in Adjudication 1.

The decision

In considering the issues Mr Justice Edwards-Stuart ruled that

"Absent fraud, in the absence of a payment or payless notice issued in time by the employer, the contractor becomes entitled to the amount stated in the interim application irrespective of the true value of the work actually carried out. The employer can defend itself by serving the notices provided for by the contractual provisions."

In addition he found that any attempt to avoid the absence of a proper notice by going back over old ground and revisiting the amount in the relevant valuation in another adjudication was not permitted. The dispute relating to Application No. 13 had been dealt with in Adjudication 1.

In short the failure by the employer to serve a payless notice in time must be taken to be the employer agreeing the value stated in the application, right or wrong. Therefore, ISG was entitled to both enforcement of Adjudication 1, and also a declaration that Adjudication 2 was invalid for want of jurisdiction as it decided a question that, as between the parties, must be taken to have been decided by him in Adjudication 1.

Matthew Harding (t/a M J Harding Contractors) v Paice & Anr2

This general principle was distinguished in the case of Harding v Paice, heard again by the same judge (albeit that this case was heard before ISG v Seevic).

The facts

Paice were property developers who engaged Harding to carry out residential works to two properties in Surrey under the terms of a JCT Intermediate Building Contract 2011.

For various reasons Harding gave notice to terminate the contract part way through the works. The termination provisions provided that Harding was required to submit a final account in respect of the work it had carried out, including the total value of the work properly executed up to the date of termination. Paice was to pay the amount that was "properly due" in respect of the account within 28 days of submission of its final account.

Paice did not make payment, and failed to serve a valid payless notice. Harding adjudicated, in response to which Paice issued counter-adjudication proceedings in an attempt to revalue Harding's final account.

Harding then applied for an injunction to prevent the counter-adjudication from proceeding, arguing that the failure by Paice to serve a valid payless notice meant that the sum in its final account became the amount that was "properly due" under the contract. Harding further argued that the substance of its account had been already referred to adjudication and it could therefore not be revisited.

The decision

Mr Justice Edwards-Stuart noted that in the relevant contract the payment provisions following termination were different from the interim payment machinery in the contract, in that they did not require the employer to pay the amount stated (i.e. the notified sum). Instead, the employer was to pay the amount "properly due" in respect of the account, in order to reflect the reckoning process that is inherent in final accounts.

The judge further noted that the adjudicator had concluded that in the absence of a valid payless notice Paice had to pay the amount stated in Harding's account.

Mr Justice Edwards-Stuart disagreed with the adjudicator's approach. Such a conclusion, he said, would deprive the employer forever of the right to challenge the contractor's account, and in some cases (for example, if the contractor had considerably overvalued its account), the contractor would be permitted to receive a windfall to which he would otherwise not be entitled, and which the employer could never recover.

In terms of the jurisdiction argument it was held that the adjudicator had not determined the amount "properly due" to Harding. He had decided that the absence of a valid payless notice automatically meant that the sum claimed in the final account was due and had to be paid, which was a different matter.

Galliford Try Building Ltd v Estura Ltd3

Mr Justice Edwards-Stuart was being kept busy by such matters and a couple of months after these first two cases, another adjudication enforcement action – Galliford v Estura relating to the lack of a payless notice – called before him.

The facts

Very late in the construction programme Galliford issued its Interim Application for payment No. 60 ("IA60"). It was for a sizeable amount and included an anticipated Final Account. The value of the work in IA60 was only £4,000 short of the amount anticipated in the Final Account, which was just short of £4m. Estura served neither a payment notice nor a payless notice. Estura didn't pay, Galliford commenced adjudication proceedings, and the adjudicator awarded the full amount of the notice to Galliford.

What to dispute? In this case the dispute was less about payless and more about the enforcement process itself. Estura accepted Galliford was technically entitled to the sum stated in the application.

It submitted, however, that there were exceptional circumstances in this case which meant that it should not have to submit to summary judgement in respect of the sums awarded by the adjudicator, as Estura:

(i)   would not get an opportunity, by way of adjudication, to challenge a palpably wrong interim application as IA60 essentially covered Galliford's valuation of the job and there was no incentive for them to do any further work (either with regard to contractual process or in respect of physical works), and

(ii)  could not afford to pay the amount of the award and enforcement would lead to insolvency which would deprive it of its right to pursue correction of the decision.

The decision

Mr Justice Edwards-Stuart appeared to be quite vexed about the circumstances of this case. He agreed with both the above arguments raised by Estura that there were unusual circumstances in this case and that it would be unable to pay the adjudicator's award in full if ordered to do so.

The court had two options. First, to take a robust approach and refuse to grant a stay on the grounds that to do otherwise would be contrary to the policy of the court to enforce the decisions of adjudicators. Galliford could then either force insolvency or negotiate some sort of compromise. Or second, to stay enforcement of all or part of the amount of the judgement.

The decision in the end was that due to "the very unusual circumstances of this case" it would not be fair on Estura to refuse a stay. However, only a partial stay was granted with enforcement of £1.5m allowed. Such action by the court, it was stated, would be appropriate only in rare cases.

Caledonian Modular Ltd v Mar City Developments Ltd4

In Caledonian v Mar City some important housekeeping was done in respect of how to determine whether a valid application for payment has been made by a contractor.

The facts

Caledonian engaged Mar City to carry out construction works at Colindale in North London.

Caledonian issued an application no. 15 seeking a net payment £1.5m. Mar City issued a valid payless notice indicating a net payment of £6,317.07. Two weeks later, under cover of three e-mails, Caledonian issued some documents to Mar City ("the Emailed Submission") including a further copy of application no. 15 prefixed with the words "Final Account". In this the net payment claim increased by around £6,000. Caledonian did not substantially respond to Mar City's subsequent requests for clarification other than to describe the submission as an "update". Mar City took no action in respect of the Emailed Submission.

An application for payment, referenced as no. 16, was issued by Caledonian four weeks later, in response to which Mar City issued a valid payless notice.

Caledonian subsequently claimed that the Emailed Submission had in fact been application for payment no. 16 and that in the absence of a payless notice they were entitled to the sum claimed. The dispute was referred to adjudication. The adjudicator agreed with Caledonian.

In the following enforcement proceedings Mar City contended that the Emailed Submission was not a valid application for payment.

The two main issues to be decided were as follows:

(i)   Did Caledonian's Emailed Submission amount to an application for interim payment?

(ii)  In an enforcement application could the court decide a substantive issue that was before the adjudicator i.e. the status of the submission, or was the court restricted simply to either enforcing or not enforcing the second adjudication decision?

The decision

On the first issue, the Judge found that the Emailed Submission was not an application for payment or a valid payee's notice:

(i)   none of the emails or the documents sent stated that this was an application for interim payment;

(ii)  subsequent correspondence did not indicate that it had been an application for payment; and,

(iii) at the time Mar City repeatedly asked Caledonian what the documents were. In response Caledonian did not state that the documents were an application for payment.

The Judge disagreed that a contractor can "update" an application by a few thousand pounds when the overwhelming bulk of that application had already been the subject of a valid payless notice. He observed that this could lead to contractors regularly applying every few days with "updated" applications in the hope of gaining windfall through the employer slipping up by failing to serve a payless notice. It had to be clear, and the employer had to be on notice, that documents intended to be an application for payment were properly identifiable as such.

On the second issue, the Judge stated that at the enforcement stage the court could deal directly with an issue decided by the adjudicator, if as here, the issue was short, self-contained, and required no oral evidence or any other elaboration beyond what was capable of being provided during a short interlocutory hearing. Therefore the second issue could be decided by way of a declaration by the court.

Henia Investments Inc v Beck Interiors Ltd5

Finally, Henia v Beck, before Mr Justice Akenhead, in Part 8 proceedings for declaratory relief, gave further consideration to the issue of the timing of not only a payless notice but also applications for payment and the interim certificate.

The facts

Henia engaged Beck to carry out extensive fit out works to a property in Kensington using the JCT Standard Building Contract without Quantities 2011 ("the Contract"). The contract provided that the interim payment due date was the 29th of each month with interim applications to be made no later than 7 days before the due date. The contract Administrator ("CA") was required to issue an Interim Certificate no later than 5 days after the due date. The final date for payment was 28 days after the due date and any payless notices were to be issued no later than 3 days before the final date.

On 28 April 2015 i.e. 6 days late, Beck submitted a document described as "Interim Application for Payment No 18". The CA issued Interim Certificate No 18, one day late, on 6 May 2015.

Beck did not submit an interim application during May 2015 but at 00.03 am 4 June 2015 – i.e. one day late – the CA issued Interim Certificate No 19 certifying a payment to Beck of £18,893.53. On 17 June 2015, Henia issued a payless notice stating that Beck's entitlement was nil.

Beck contended that the document submitted on 28 April 2015 comprised a valid interim application relating to the 29 May 2015 due date and that because the CA's Interim Certificate was late, this meant that the amount claimed on 28 April was now due. Beck further argued that the payless notice issued by Henia on 17 June was invalid on grounds that in such a notice Henia could only apply cross-claims like liquidated damages and not otherwise challenge the CA's valuation.

The decision

The Judge found that in order for there to be no question as to the validity of an interim application for payment, it needs to be clear and unambiguous. Beck's 28 April 2015 document could not therefore be treated as a valid Interim Application in relation to the 29 May 2015 due date where: (i) there was a relevant due date on 29 April 2015, which would have been the 18th relevant due date under the contract; (ii) there was nothing in the 28 April document that suggested a due date of 29 May 2015; (iii) there was no indication in the 28 April document to suggest that the 29 April due date had been missed and that the document was intended to relate to the 29 May due date; and, (iv) the 28 April document was not in substance, form and intent an Interim Application relating to the 29 May 2015 due date.

Whilst acknowledging that it was now a superfluous issue, the judge decided that if the 28 April document did not relate to the 29 May 2015 due date there was nothing in the contract to prohibit the employer from challenging a valuation certified by the CA.

Finally it was found that any failure by the CA to operate the extension of time provisions would not give rise to a condition precedent debarring Henia from claiming liquidated damages. Any potential short term unfairness to Beck could be resolved through the relevant contractual dispute resolution mechanisms. The Judge stressed that this finding was obiter where prior to judgment being handed down, in adjudication proceedings commenced by Beck, the Adjudicator had decided that no valid application for an extension of time had been submitted.

Commentary

Other than the focus on payment provisions themselves, a theme that was prevalent in these cases was that the intent of the Construction Act, and the regime it has put in place, should be preserved as much as is possible and practicable. The assumption might be that this philosophy will always favour the contractor, focused as it is on maintaining cashflow. Whilst this is crucial, what the cases of Galliford v Estura and Caledonian v Mar in particular show is that the situation is not one sided, and protection of employer/client interests, is just as important a consideration.

The cases this year leave some questions still on the table, however, there is a good solid framework against which employers and contractors alike can manage their risks around the payment provisions of their contracts.

Footnotes:
1. [2014] EWHC 4007 (TCC)
2. [2015] EWHC 661 (TCC)
3. [2015] EWHC 412 (TCC)
4. [2015] EWHC 1855 (TCC)
5. [2015] EWHC 2433 (TCC)

This article is taken from Fenwick Elliott's 2015/2016 Annual Review. TO read further articles go to www.fenwickelliott.com/research-insight/annual-review/2015

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions