Worldwide: Risks Analysis Under Construction And Engineering Contracts*

Last Updated: 10 August 2011

Article by Mr Saleh Majid (Advocate (Iraq), Rechtsbeistand (Germany) for business laws of Arab countries, B.A.Law (Baghdad), Dip.Air Law, Postgrad Dip.Law (London), M.C.I. Arb.


Statistics show that construction projects are often exposed to risks and hazards, arising either from purely contractual and legal problems or unforeseen circumstances or natural hazards. Often, contractors are faced with unexpected events, which were not calculated in the offer and the programme of works, leaving the contractor with unforeseen costs and losses.

A decision whether to calculate the risks or not in the offer is a matter of policy and market conditions. If the contractor calculates most of the risks and prices them, then most probably, he is out of the race. If he does not calculate and the risk is fatality, it will any way put the contractor out of business. The industry is well advised not to place all the risks on the contractors by drafting extremely one-sided contracts. To do so would ultimately keep away efficient and prudent contractors from tendering for projects, and would lead to higher tender prices.

Risks should not be ignored, and contractors are also well advised to evaluate during the tendering period the risks whether contractual, political, or social by preparing an appropriate contract and risks analysis as well as a local market study. They are advised to calculate certain risks, and allocate other risks to suppliers, subcontractors, and insurance policies.

As a first step, risks should be recognised and assessed. This is the route to an efficient management of risks. Once a risk is identified and assessed, decisions may be taken to transfer it or share it with other parties or accept it and manage it. The role of an experienced lawyer to identify contractual risks, prepare reservations to be submitted with the offer to the employer is vital, though may be disliked by many engineers and marketing managers who are too keen to secure a contract.

Definition: Risks may be defined as an event or a situation which probably occurs during the lifetime of a project or contract that has potential consequences of damage to property or environment, or personal injury, and/or financial loss or loss of time.

It is worthwhile to mention that not all the risks are real and severe. A risk has several aspects to consider:

First, how frequent it occurs and how far probable and immanent it is. Here, different rates can be given according to whether the risk is: certain, or very remote or fairly possible.

Secondly, how severe is the effect if the risk occurs. Is it within the margin calculated for overhead charges and usual contingencies, or is it manageable, or is it a serious loss and catastrophic?

In general, the risks and contingencies in any construction and engineering contract may be classified to:

  1. Risks which the contractor should bear. They include:

    • the risks which the contractor can control by good management and planning, or
    • risks which the contractor may insure and calculate the costs in his offer, such as risks of personal injury, damage to equipment, and even political risks arising from acts of government, and
    • risks which the contractor may pass to others, such as manufacturers and suppliers, for example design, workmanship and maintenance risks

  2. Risks and contingencies which the contractor should measure and attempt to shift to the employers, such as risks of force majeure, war risks, risks of unforeseen conditions. One of the common contractual risks in contracts prepared by the lawyers of employers is to impose on the contractor a liability to pay penalties or liquidated damages without a ceiling or limit for delay in completing the works. Another contractual risk is to hold the contractor liable for damage or injury arising from the contractor's default or negligence without any limitation.

    Fortunately, employers are often inclined to negotiate those aspects of the contract. Therefore, contractors are advised to place reservations in their offers proposing a certain limit or ceiling for the liquidated damages or penalties for delay and another ceiling for the contractor's total liabilities.

    Furthermore, an important aspect of risks management is through concluding the right insurance policies, especially in respect of risks which are common to occur or catastrophic when they occur. But, management of risks by insurance is a creative and difficult task, which requires a proper analysis of the conditions of the construction contract as well as the conditions of the insurance which are fully decorated with exclusions and exemptions.

The risks

The risks analysis in this study is mainly based on the use of the FIDIC Conditions of Contract for Works of Civil Engineering Construction, 4th Edition. These Conditions of Contract are most widely used in international projects. Though FIDIC has issued new editions of the said conditions of contract, the risks outlined in this article remain valid to a large extent. It is necessary to recognise and manage such risks, even if the employer has accepted some of the risks under the new FIDIC conditions.

Many Middle Eastern countries such as Iraq, Egypt, Kuwait, Saudi Arabia and UAE, have issued standard General Conditions of Contracts which are used for government projects. Those standard General Conditions were generally based on the provisions of FIDIC, 4th edition. Thus, the risks analysis here is applicable to projects in the Middle East as well as other projects. It is also applicable to contracts using FIDIC standard form, and to a lesser extent to other forms of construction and engineering contracts. The writer was the chairman of the Committee, which revised and drafted the Iraqi General Conditions of Contract, which were based on the 4th edition of FIDIC General Conditions for Electrical and Mechanical Work, and the FIDIC General Conditions for Civil Construction Work.

By virtue of the provisions of the Iraqi Regulations no. 1 of 2008 for Execution of Government Contracts, Iraqi government entities are bound to announce tenders and conclude contracts based on the Iraqi Government Standard Conditions of Contract referred to here above.

Risks of construction and engineering projects are many, due to the number of the parties involved, differing tasks of the contractor, engineer, employer, subcontractor and the inherent nature of the works. The following is an outline of a list of risks and contingencies which contractors may face during execution of projects:

A. Adverse Physical Conditions or Obstructions

  • Conditions of the ground water, and soil conditions
  • Pipes and services, or even bombs left gracefully by someone somewhere in the land or water
  • Wells, pits, shafts, boreholes, etc.
  • Contaminated ground
  • Fossils and antiquities

B. Delay and Disruption

  • Due to late handing-over of the site by the employer
  • Late working drawings, instructions, issued by the engineer
  • contractor's inefficiency, breakdown, or lack of machinery and equipment
  • Nominated sub-contractor's inefficiency
  • Delay outside both parties' control
  • Labour disputes

C. Defective Materials or Workmanship of Contractor

  • Defective materials or workmanship of a domestic or nominated sub-contractor or supplier
  • Costs of Tests and Samples required by the engineer

D. Direction and Supervision by the Employer or the Engineer

  • One-sidedness of the employer or the engineer
  • Incompetence
  • Inefficiency
  • Unreasonableness
  • Lack of communication
  • Ambiguity or contradiction between documents prepared by the engineer or misleading description in the bill of quantities etc.
  • Dispute on Methods and Measurement
  • Defective design of temporary or permanent works by owner or consultant, contractor or domestic or nominated sub-contractor or supplier

E. Damage and Injury to Persons and Property:

  • Due to negligence or breach of warranty of contractor in designing or in temporary works, building permanent works or otherwise
  • Due to negligence of consultant or owner in design or supervision
  • Due to nominated subcontractor's or supplier's negligence or breach of warranty
  • Due to matters outside the parties' control but which are insurable
  • Due to uninsurable risks – war, riots, rebellion, etc.
  • Consequential losses arising from above
  • Exclusions, gaps and time limits in insurance cover

F. Shortage of Resources:

  • Shortage of staff, labour, plant, materials
  • Shortage of finance and liquidity

G. Government Policy and Change of Legislation

  • Taxes, labour, safety or other laws
  • Delay or refusal of planning approval for works or temporary works
  • Foreign Exchange Restrictions
  • Financial constraints by the Government
  • Potential political instability

H. Conflicts and war:

  • Cost of war, civil commotion, malicious damage, etc.

I. Labour Demands and Unrest:

J. Payment:

  • Devaluation
  • Delay in settling claims and certifying
  • Delay in paying certificates
  • Legal limits on recovery of interest
  • Insolvency of contractor, sub-contractor or owner
  • Funding constraints
  • Shortcomings resulting from the measurement and valuation process
  • Governmental delay in payment and budget deficit

K. Inflation:

  • Absence of an escalation clause in the Contract
  • Any element of cost or profit not covered by a price fluctuation clause
  • Replacement cost of plant and equipment – especially in countries where inflation is high such as Latin America

L. Arbitration and Law:

  • Delay in resolving disputes
  • Uncertainty of result due to lack of records, unfair or ambiguous contract, or inefficiency of legal process, and even lack of the due process of law
  • Costs of arbitration and litigation
  • Enforcement of the decision.

The foregoing list of risks and contingencies is not comprehensive. And as stated before, it is left to contractors and to the market conditions to see which of those risks should be calculated and added to the prices of the offer, and which risks should be covered by insurance, or shifted to the employer, if possible.

In fact, many international standard contracts have distributed the risks between the parties. Similarly, FIDIC Standard General Conditions of Contracts have allocated the risks between the contractor and the employer in a reasonable manner.

Many of the risks listed and referred to hereabove have been dealt with under different clauses of the FIDIC Conditions of Contract for Work of Civil Engineering Construction by granting the contractor a right to claim extra cost and/or extension of time and to cover costs and delay caused by encountering certain conditions or events.

The following is a short list of headings of clauses of the aforesaid FIDIC Conditions which allocate the risks between the employer and the contractor and entitle the contractor to claim compensation or extension of time:

  1. Risk of Design Discrepancies: Clause 5.2
  2. Risk of Delay by Engineer: Clauses 6.4
  3. Risk of Differing Site Conditions: Clauses 11 and 12
  4. The Risk of Non-conformity of Works: Clause 13
  5. The Risk of Damage to the work: Clauses 20, 21, and 22
  6. The Risk of Third Party Injury or Property Damage: Clauses 22 and 23
  7. The Risk of Delay: Clauses 41 through 44 and 46
  8. The Allocation of "Special Risks" By Limitation of Liability: Clause 65
  9. The risk of "Other Circumstances" and Frustration of the Contract: Clause 66
  10. Allocation of the Risks of Currency Restrictions and Rates of Exchange: Clauses 71 and 72
  11. The Risk of Changes in Costs and Legislation: Clause 70

Time and space are not available in order to deal with the foregoing risks and the remedies provided by FIDIC. Therefore, I have chosen to deal in some details with the risks of site conditions and delay and disruption of works as examples of risks faced by contractors:

Adverse Ground or Physical Obstructions or Conditions on the Site

The contractor is exposed to considerable risks during the execution of the work by encountering unforeseen physical and site conditions or obstructions leading to delay of the works and extra costs.

Such risks frequently occur, although not always with severe effects, for example high ground water, underground rocks, underground pipes and crossings, mines etc. These risks become more real due to the fact that the employers/owners often do not undertake a full site investigation before announcing tenders.

Furthermore, in an attempt to deprive the contractor from the right to claim compensation for costs and time resulting from such risks, conditions of tenders often place an obligation upon tenderers to make site and soil investigations and fully inform themselves before the submission of their tenders.

This trend leads to higher tender prices, and often to awarding contract to less prudent contractors with lowest tender prices, which may prove later to be less qualified for the job.

Thus, employers and owners are well advised to make full soil and site investigations before tendering and accept the liability for the unexpected soil and site conditions. This will in the end cause the tenderers to lower their prices. This advice would apply to some other risks which the employers may be more capable to deal with.

Clause 12 of the FIDIC General Conditions for Civil Works, 4th edition, has attempted to allocate and distribute the risks between the contractor and the employer. This is one of the areas where claims are often submitted by the contractors and disputed by the employers.

Clause 12 stipulates that the contractor is required to have satisfied himself that his tender and rates and prices are correct and sufficient and that they cover contingencies and everything that the contractor has to do to complete the Contract.

This imposes a serious obligation on the contractor, especially if we consider that the tendering period is normally too short that a contractor cannot carry out such a proper site and market investigation.

How far such a provision is enforceable depends on the legal system and the judge adjudicating the case. In general, the criteria of reasonableness and practicality should apply in my opinion, and no contractor is expected to carry out an extensive ground and underground investigation during a short tendering period.

Fortunately, clause 12.2 continues and offers a partial remedy. If the contractor encounters physical obstructions or conditions (other than bad weather) which an experienced contractor could not have foreseen, he may give notice to the engineer.

Upon consultation with the employer and the contractor, the engineer may grant the contractor an extension of time and appropriate costs resulting from such physical obstructions or physical conditions which the contractor could not foresee.

Requirements for Application of Clause 12.2

In order to apply this clause and claim extension of time and costs under this clause, the contractor must prove three matters, namely, that

  1. He has encountered physical obstruction or physical conditions apparently on Site, other than climatic conditions
  2. These Conditions could not have been foreseen by an experienced contractor
  3. They have caused him additional costs and delay
  4. In addition to the above, the contractor must give notice of his intention to claim to the engineer within 28 days from the date of the event. He must also submit detailed particulars to the engineer within 28 days from the first notice.

    The criterion of the site conditions being unforeseen by an experienced contractor is vague; therefore it is subject to different interpretations by judges and arbitrators.

Delay, Disruption of the Works

Delay and disruption of the works are the most frequent and common risks which contractors encounter. The reasons for delay and disruptions may be classified in three groups as follows:

  1. Events caused by the employer or the engineer or other contractors such as delay in handing over the site, or delay by employers, or by other contractors to complete the civil work, or delay by the engineer to issue or approve the drawings.
  2. Events caused by the contractor or by someone for whose act the contractor is responsible such as his subcontractor or supplier.
  3. Events or persons causing delay for which or for whom neither party is responsible such as weather conditions or natural events, or war or unexpected geological or ground conditions, as stated before.

Delays may cause the contractor to suffer a wide variety of loss or damages such as stand-by time costs, losses in productivity, increased cost by inflation and the disruption of the whole programme of the Works. In addition, he may have to pay the employer liquidated damages as may be stated in the Contract. The risk of paying liquidated damages becomes more serious if the Contract does not provide for a ceiling or a limit for the liquidated damages. The payment of liquidated damages for delay by the contractor is binding under many jurisdictions, if stipulated in the Contract, even if the employer suffers less loss or no loss at all.

Under certain circumstances the contractor may have the right to claim extension of time or claim extension of time and compensation for additional costs if the delay is caused by the employer or the engineer or by reasons for which neither the contractor nor the employer is responsible, such as under clauses 6.3, 42, 44 and clause 65 of the FIDIC Conditions, 4th edition.

In general, the contractor is in principle entitled to recover from the employer his costs on the basis of a breach of contract by the employer or under an express or implied term of the Contract. For example in cases of the failure of the employer to obtain in time land owners' permission to enter the site or delay in supply of materials by the employer, or delay by the engineer to issue the necessary drawings...

In such cases, where the delay is caused by the employer or his engineer, the employer has no right, unless otherwise stated in the Contract, to order the contractor to accelerate to make up for the lost time.

But where the delay is due to contractor's default, then the contractor has a duty to mitigate the delay by taking reasonable measures including acceleration, and he is not entitled to choose to be late and pay liquidated damages.

FIDIC Conditions of Contract provides contractors with a number of possibilities to claim extension of time and/or compensation.

Extension of Time, Clause 44 of FIDIC, 4th Edition:

Clause 44.1 stipulates five reasons upon which the contractor may claim extension of time. But it is left to the engineer to evaluate the reason for delay and the effect on the progress of the work. He is expected to act impartially and in a fair manner, but in practice he may be reluctant to admit that he has himself caused the delay, for instance in granting approvals or providing the necessary drawings.

These reasons are:

  1. Extra or additional work, including variations under clause 51
  2. Any cause of delay referred to in the FIDIC Conditions such as delay in possession of the site, clause 42
  3. Exceptional adverse climatic conditions, as in clause 12
  4. Any delay, impediment or prevention by the employer. This is a new provision which appears in the FIDIC fourth edition.
  5. Other special circumstances which may occur other than through a default or breach of Contract by the contractor, such as special risks under clause 65.

Special circumstances are not defined and may lead to many disputes. There is a tendency to interpret special circumstances as circumstances of force majeure which could not have been expected by the contractor, such as war or riots or damage of a drilling rig, or shortage of fuel.

The contractor, in order to exercise his rights to claim extension of time under clause 44.1, must follow the procedures and keep the time limits as laid down in clauses 44.2 and 44.3.

Compensation for Extension of Time:

It is worthwhile to notice that clause 44 provides the contractor with a right to claim extension of time only, and the contractor has no right under this clause to claim additional cost unless he can justify his claim under another provision of the contract or under the general law.

In fact there is no general clause in the FIDIC Conditions, 4th edition, which deals in a comprehensive manner with the right of the contractor to compensation in case of delay.

Nevertheless, a number of clauses can be identified which provide the contractor with a right to claim costs or extra payment for delay as stipulated under the following clauses:

  • Clause 6.4, Cost of delay by the engineer in issuing drawings
  • Clause 40.2, Cost of suspension of work by the engineer
  • Clause 42.2, Cost of delay by the employer in handing over the site
  • Clause 12.2, Cost resulting from adverse physical conditions or obstructions.

As we have seen, the risks in construction contracts are many but it is only by risking ourselves from one hour to another that we live at all.

N.B. The writer, in preparing this article, has particularly relied on the following references among other references:

  • Dr. Nael G. Bunni, The FIDIC Form of Contract, Second Edition, Blackwell Science.
  • Philip Bruner, Allocation of Risks in International Construction..., International Construction Law Review, Vol. 3, Part 3, April 1986
  • Max Abrahamson, Risk Management, International Construction Law Review, Vol. 1, April 1984
  • Keith Pickavance, Delay and Disruption in Construction Contracts, LLP, 1997


* This is a revised version of a speech delivered by the writer during the Second German-Arab Economic Forum held on 25th June 1999 in Berlin, and it was published in Middle East Executive Report, Jan. 2000

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions