Canada: Adjudication Watch June 2018 - Caselaw Review And Update: What You Need To Know

In this latest 'Adjudication Watch' our construction team provides updates on significant adjudication decisions:

What is the potential effect of the responding party seeking to limit its defence to specific issues?

Mailbox (Birmingham) Ltd v Galliford Try Building Ltd (formerly known as Galliford Try Construction Ltd) [2017]


Mailbox employed Galliford Try to design and construct a development in Birmingham under an amended JCT form of contract. A dispute arose. Simplifying the background, in March 2016, Mailbox commenced an adjudication (number one) seeking a declaration that it was entitled to liquidated damages (LDs) of approximately £5m (its entire claim for LDs).

In adjudication one, Galliford Try stated that it was limiting its defence to specific issues; outside the adjudication however, it served a "full" extension of time claim. The adjudicator considered that the adjudication could not be so restricted by the terms of Galliford Try's defence and awarded Mailbox significant LDs. Galliford Try did not pay.

In adjudication two, Galliford challenged the lawfulness of the termination of contract and relied on claims for extensions of time. By way of challenge to adjudication two, in these proceedings, Mailbox sought a declaration that adjudicator one had decided the entitlement to LDs and so, no subsequent adjudicator had jurisdiction to consider further extension of time claims made by the contractor.


The court held that Mailbox's entitlement to liquidated damages was final and binding unless/until the decision was overturned by a court. Consequently, a claim for an extension of time became redundant - as the dispute in adjudication one included all time-related issues, they could not therefore be re-visited in a subsequent adjudication (but could be re-considered in later court proceedings).

Termination had not been part of the crystallised dispute in the first adjudication and therefore, a second adjudicator could consider all issues relating to whether or not the contractor was proceeding regularly and diligently with the works. (Mailbox's financial entitlement following the first adjudication would remain unaffected.)

In the view of Mr Justice Coulson (as he then was), the contractor "...chose to stick to a high-risk policy of attempting to dictate which of their extension claims were in and which were not. In the event, that has proved an unwise course."

This decision highlights the need to choose your strategy wisely - as defendant in an adjudication, limiting your line of defence can prejudice you going forward (as you may lose your right to argue the balance of issues at a later stage).

Compare this with the position of a claimant in adjudication who potentially has more scope for cherry picking the issues to be considered by the adjudicator at the outset, although a claimant seeking to limit the scope of any adjudication has to accept that a responding party can defend itself on the basis of any available defences.

If a party reserves its rights on jurisdiction but then takes part in the adjudication, what is its contractual position with the adjudicator?

Christopher Linnett Ltd and Mr Christopher Linnett v Matthew J Harding [2017]


This dispute arose following Mr Linnett's appointment as adjudicator in a dispute between MJH, a building contractor, and MJH's employer under a building contract. At the outset of the adjudication, MJH had reserved its rights pursuant to a jurisdictional challenge, declined to accept the adjudicator's terms, but went on to take part fully in the adjudication.

In enforcement proceedings, MJH was ordered to pay monies to the employer, and also, a half share of the adjudicator's costs. In these proceedings, Mr Linnett claimed interest and related amounts following the delay in payment of his fees.


One of the issues to be decided was whether or not there was a concluded agreement between MJH and Mr Linnett. The court held that, notwithstanding MJH's reservation of rights, there was a concluded contract between MJH and Mr Linnett which arose from conduct, following the full participation by MJH in the adjudication. This was a commercial contract on the adjudicator's terms falling within the ambit of the Late Payment of Commercial Debts (Interest) Act 1998, therefore entitling the adjudicator to recover interest, statutory compensation and debt recovery costs.

This decision highlights the need to be aware that even if you reserve your position on jurisdictional issues, taking part in an adjudication (which is often the only pragmatic approach) may result in a concluded contract with the adjudicator, with attendant rights and obligations.

Does an adjudicator's appointment lapse after the date for the decision, if no decision is issued by that date?

Baldwin and another v J R Pickstock Ltd [2017]


Mr Baldwin was appointed as adjudicator in a dispute involving Pickstock and another contractor (M). The progress of the adjudication was scattered with numerous jurisdictional challenges and procedural disagreements. In particular, the parties had agreed that the adjudicator's decision should be delivered by 27 May 2016. In due course however, the adjudicator asked for an extension to 7 June 2016 - Pickstock's representatives remained silent on this issue until 31 May (ie after the original date of 27 May), at which point Pickstock refused to agree the extension of time to 7 June.

As a result, on 9 June 2016, the adjudicator purported to resign before issue of his decision. In doing so, he stated that Pickstock's silence in relation to the requested extension of time led him reasonably to believe that the extension had been agreed.

In these proceedings, the adjudicator sought to rely on clause 3.2 of his appointment which provided (in summary) that if he should resign before reaching a decision due to jurisdictional challenges, the Referring Party would be liable for his fees - as a result, it was argued Pickstock was liable for those fees, following the purported resignation.

Pickstock's position was that the appointment lapsed once the date for delivery of the decision passed and therefore there was nothing from which the adjudicator could resign as at 9 June. Accordingly, it was argued, the adjudicator's claim for fees based on clause 3.2 of the appointment should fail.


The conduct of Pickstock's representatives on this issue was described by the Judge as "reprehensible". Based on previous caselaw, they were taken by their silence to have acquiesced to the extension of time to 7 June 2016. However, after this date, the adjudicator's appointment lapsed and therefore the adjudicator's attempt to resign on 9 June was invalid and he could not recover the sum claimed.

According to the court's decision, had the adjudicator resigned on 6 June 2016, the outcome would have been very different.

The decision highlights:

  1. If an adjudicator's decision is not issued by the specified date, the adjudicator's appointment will lapse after that specified date - no specific act is needed to bring the appointment to an end.
  2. Don't assume that you can reserve your position in these circumstances by simply remaining silent - the court made it clear that it is incumbent on a party to respond promptly to an adjudicator's request for an extension of time. If you fail to respond, you could be taken to have acquiesced in any event.

To what extent can an adjudicator consider arguments/issues not put forward by the parties?

Victory House General Partner Ltd v RGB P&C Ltd [2018]


This dispute arose out of a design and build contract for the conversion of a hotel in Leicester Square. In these proceedings, RGB (the contractor) sought to enforce an adjudicator's decision in its favour against Victory (the employer).

The only issue considered by the court at this time related to a contention that there had been a breach of natural justice by the adjudicator, in that his decision did not reflect an argument that had been put forward by either party and so the adjudicator was "going off on a frolic of his own" in terms of the construction of a Memorandum of Agreement between the parties.


This contention was firmly rejected by the court as the adjudicator had specifically invited both parties to make submissions on the clauses in issue. Even if that had not been the case, the decision turned on contractual interpretation and following previous caselaw, he could make a decision that did not necessarily reflect a submission made by either party in any event.

The decision highlights the need to give very careful consideration to queries raised by an adjudicator inviting further submissions - if you choose not to make substantive submissions in response, you may not get a later opportunity.

In this dispute, Victory chose not to respond to the queries raised (re-asserting rather the factual background) so could not complain later that it had not been given the opportunity to address a particular point.

Read the original article on

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Events from this Firm
19 Sep 2019, Seminar, Birmingham, UK

Providing GCs, Heads of Legal and senior in-house lawyers with timely, topical and practical legal advice on a variety of topics.

26 Sep 2019, Seminar, London, UK

Providing GCs, Heads of Legal and senior in-house lawyers with timely, topical and practical legal advice on a variety of topics.

8 Oct 2019, Seminar, Birmingham, UK

Supporting the development of paralegals, trainees and lawyers of up to five years' PQE by providing valuable knowledge and guidance together with practical tips.

Similar Articles
Relevancy Powered by MondaqAI
Osler, Hoskin & Harcourt LLP
In association with
Related Topics
Similar Articles
Relevancy Powered by MondaqAI
Osler, Hoskin & Harcourt LLP
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions